What are the most common causes of construction delays in Queensland?

Unforeseen site conditions, extreme weather events, supply chain disruptions, and contractual disputes can cause construction delays. Homeowner-requested design variations, council approval delays, and late progress payments can also contribute to project setbacks. Builders may also face labour shortages, material unavailability, or errors in architectural plans that impact the timeline. Understanding the cause of a delay is crucial in determining whether an extension of time (EOT) can be granted and if compensation applies.

When is a builder entitled to an extension of time (EOT)?

A builder is entitled to an EOT if the delay is caused by circumstances beyond their control, such as extreme weather, supply shortages, or council approval delays. To qualify, the delay must be excusable and meet contract provisions, and the builder must notify the homeowner in writing within the required timeframe. The claim should accompany supporting evidence, such as weather reports or supplier notices. If the builder fails to follow the correct procedure, the EOT may be rejected, leading to potential liability for liquidated damages.

What happens if a builder fails to complete the project on time?

If a builder does not meet the Date for Practical Completion and has not been granted an EOT, they may be liable for liquidated damages as outlined in the contract. The homeowner may also claim general damages if they can prove actual financial losses, such as increased rent or storage costs. In severe cases of prolonged delays, the homeowner may have the right to terminate the contract and seek further compensation. Builders who experience unavoidable delays should follow proper documentation and notification procedures to avoid financial penalties.

Can homeowners claim compensation for construction delays?

Yes, homeowners may claim liquidated damages if the contract specifies a pre-agreed daily penalty for late completion. If no liquidated damages clause exists, they may seek general damages, but they must prove actual financial loss due to the delay. Compensation claims depend on whether the delay is excusable or non-excusable and whether the builder has followed contractual obligations. If disputes arise, homeowners can lodge a complaint with the QBCC or escalate the matter to QCAT for resolution.

What is the Prevention Principle, and how does it affect construction delays?

The Prevention Principle states that a party cannot enforce contract penalties for a delay they caused. If a homeowner fails to approve design variations, delays material selections, or restricts site access, they may be prevented from claiming liquidated damages against the builder. In such cases, time may be set “at large,” meaning the builder is only required to complete the project within a reasonable timeframe rather than the original deadline. To avoid disputes, builders should document all delays caused by the homeowner and formally request an EOT.

How do supply chain disruptions impact construction contracts?

Material shortages and delivery delays can halt construction progress and create unexpected costs for builders and homeowners. Under Queensland construction law, supply chain disruptions may qualify for an EOT if unforeseeable and beyond the builder’s control. However, the builder may not be entitled to an extension if the delay was foreseeable when signing the contract. Builders should document supplier notices and attempts to source alternative materials to support any EOT claims.

What should be included in a construction contract to manage delays?

A well-drafted contract should include clear provisions for delays, outlining when extensions of time (EOTs) apply and whether liquidated damages will be enforced. It should also specify notification requirements, such as how and when the builder must inform the homeowner of a delay. The contract should define approvals, material selections, and site access responsibilities to prevent disputes over delay claims. Having a construction lawyer review the contract before signing can protect both parties’ rights.

What are liquidated damages in construction contracts?

Liquidated damages are a pre-agreed financial penalty set in the contract that applies if the builder fails to complete the project on time. The amount is usually calculated per day of delay and should reflect a genuine estimate of the homeowner’s potential loss. Queensland courts may rule excessive liquidated damages as unenforceable, so the agreed amount must be reasonable. Homeowners should include a liquidated damages clause in their contract to safeguard against project overruns.

How can builders protect themselves from delay-related disputes?

Builders should keep detailed records of all communications, site conditions, material deliveries, and project progress. Properly documenting weather disruptions, supply chain issues, and homeowner-caused delays can support EOT claims and defend against liquidated damages. To avoid potential liability, builders must submit EOT requests on time and ensure that all contractual obligations are met. In the event of a dispute, seeking mediation through the QBCC before escalating to QCAT can help resolve issues efficiently.

Can a homeowner terminate a contract due to excessive delays?

Yes, a homeowner may have the right to terminate the contract if delays are prolonged, unreasonable, and not excused by an EOT. Before terminating, they must follow the contract’s dispute resolution procedures, including giving the builder formal notice and an opportunity to rectify the delay. If the contract includes a termination clause for excessive delays, this will determine the proper legal process. Seeking legal advice before terminating can prevent wrongful termination claims from the builder.

How can construction delays be prevented?

Delays can be minimised by establishing clear timelines, maintaining strong communication, and managing risks proactively. Homeowners should ensure that design approvals, material selections, and payments are made on time to avoid unnecessary hold-ups. Builders should implement effective project management strategies, such as scheduling trades efficiently and securing materials in advance. Both parties should consider alternative dispute resolution methods (ADR) to resolve potential delays before they escalate into costly legal disputes.

What role does the QBCC play in resolving construction disputes?

The Queensland Building and Construction Commission (QBCC) provides mediation services for homeowners and builders to resolve disputes before taking legal action. If an agreement cannot be reached, the QBCC may issue a binding decision or refer the matter to QCAT. The QBCC can also discipline builders who repeatedly fail to meet contractual obligations, including suspending licences. Homeowners and builders should attempt to resolve disputes through the QBCC before escalating the matter to court.

How does QCAT handle construction delay disputes?

The Queensland Civil and Administrative Tribunal (QCAT) hears residential construction disputes, including claims for delays, liquidated damages, and contract breaches. It can award compensation, enforce EOTs, and terminate contracts if necessary. Before filing a claim, parties must first attempt mediation through the QBCC. QCAT provides a cost-effective alternative to litigation, making it a preferred forum for resolving delay-related disputes.

What are the risks of not correctly claiming an EOT?

If a builder fails to properly claim an extension of time, they risk being held liable for delay-related damages. If the project is significantly delayed, the homeowner may enforce liquidated damages or seek contract termination. Without proper documentation, the builder may lose the ability to defend against liability claims under the Prevention Principle. Ensuring EOT claims are submitted correctly and within the contract’s timeframe is essential to avoid financial penalties.

What should homeowners and builders do if a delay dispute arises?

Both parties should first attempt to resolve the issue through open communication and negotiation. If unresolved, mediation through the QBCC can help reach an agreement without escalating to QCAT or court proceedings. If mediation fails, the dispute may be referred to QCAT for a legally binding decision. Seeking legal advice early can help homeowners and builders understand their rights and obligations before pursuing legal action.

What are delay damages in construction?

Delay damages are financial compensation claimed when a construction project exceeds the agreed completion date without a valid extension of time (EOT). These damages compensate the affected party—typically the homeowner or developer—for financial losses caused by the delay, such as extra rent, mortgage payments, or business losses. Delay damages can be pre-agreed (liquidated damages) or assessed based on actual financial loss (general damages). To successfully claim delay damages, the contract must outline explicit provisions for delays, and the affected party must prove the economic impact of the delay.

What is the difference between liquidated damages and delay damages?

Liquidated damages are a pre-agreed fixed amount set in the construction contract, payable if the builder fails to complete the project on time. These damages are typically calculated daily or weekly, making it easier to enforce and reducing disputes over compensation amounts. Delay damages, on the other hand, refer to general compensation for actual financial losses suffered due to a project delay. Unlike liquidated damages, delay damages require the affected party to prove their losses, such as additional rent, lost income, or storage costs.

Can you charge a builder for taking too long?

Yes, suppose a builder fails to complete the project within the agreed timeframe and does not have a valid EOT. In that case, the homeowner may be entitled to liquidated damages or general damages. Liquidated damages can be enforced if the contract includes a specific clause outlining a fixed penalty for each day of delay. If no such clause exists, the homeowner may still claim general damages, but they must prove actual financial losses resulting from the delay. If a dispute arises, homeowners can seek mediation through the Queensland Building and Construction Commission (QBCC) or escalate the matter to QCAT.

What is a delay in construction contracts?

A delay in a construction contract occurs when the project does not progress according to the agreed timeline, causing completion to extend beyond the scheduled date. Delays can be excusable (e.g., extreme weather, supply shortages, unforeseen site conditions) or non-excusable (e.g., poor project management, builder mismanagement, subcontractor issues). The contract typically defines how delays are handled, including whether the builder can claim an EOT or if the homeowner is entitled to compensation for late completion. Proper documentation and adherence to contractual notice requirements are crucial in managing delays and avoiding disputes.

What are the most common causes of construction delays in Queensland?

Unforeseen site conditions, extreme weather events, supply chain disruptions, and contractual disputes can cause construction delays. Homeowner-requested design variations, council approval delays, and late progress payments can also contribute to project setbacks. Builders may also face labour shortages, material unavailability, or errors in architectural plans that impact the timeline. Understanding the cause of a delay is crucial in determining whether an extension of time (EOT) can be granted and if compensation applies.

When is a builder entitled to an extension of time (EOT)?

A builder is entitled to an EOT if the delay is caused by circumstances beyond their control, such as extreme weather, supply shortages, or council approval delays. To qualify, the delay must be excusable and meet contract provisions, and the builder must notify the homeowner in writing within the required timeframe. The claim should accompany supporting evidence, such as weather reports or supplier notices. If the builder fails to follow the correct procedure, the EOT may be rejected, leading to potential liability for liquidated damages.

What happens if a builder fails to complete the project on time?

If a builder does not meet the Date for Practical Completion and has not been granted an EOT, they may be liable for liquidated damages as outlined in the contract. The homeowner may also claim general damages if they can prove actual financial losses, such as increased rent or storage costs. In severe cases of prolonged delays, the homeowner may have the right to terminate the contract and seek further compensation. Builders who experience unavoidable delays should follow proper documentation and notification procedures to avoid financial penalties.

Can homeowners claim compensation for construction delays?

Yes, homeowners may claim liquidated damages if the contract specifies a pre-agreed daily penalty for late completion. If no liquidated damages clause exists, they may seek general damages, but they must prove actual financial loss due to the delay. Compensation claims depend on whether the delay is excusable or non-excusable and whether the builder has followed contractual obligations. If disputes arise, homeowners can lodge a complaint with the QBCC or escalate the matter to QCAT for resolution.

What is the Prevention Principle, and how does it affect construction delays?

The Prevention Principle states that a party cannot enforce contract penalties for a delay they caused. If a homeowner fails to approve design variations, delays material selections, or restricts site access, they may be prevented from claiming liquidated damages against the builder. In such cases, time may be set “at large,” meaning the builder is only required to complete the project within a reasonable timeframe rather than the original deadline. To avoid disputes, builders should document all delays caused by the homeowner and formally request an EOT.

How do supply chain disruptions impact construction contracts?

Material shortages and delivery delays can halt construction progress and create unexpected costs for builders and homeowners. Under Queensland construction law, supply chain disruptions may qualify for an EOT if unforeseeable and beyond the builder’s control. However, the builder may not be entitled to an extension if the delay was foreseeable when signing the contract. Builders should document supplier notices and attempts to source alternative materials to support any EOT claims.

What should be included in a construction contract to manage delays?

A well-drafted contract should include clear provisions for delays, outlining when extensions of time (EOTs) apply and whether liquidated damages will be enforced. It should also specify notification requirements, such as how and when the builder must inform the homeowner of a delay. The contract should define approvals, material selections, and site access responsibilities to prevent disputes over delay claims. Having a construction lawyer review the contract before signing can protect both parties’ rights.

What are liquidated damages in construction contracts?

Liquidated damages are a pre-agreed financial penalty set in the contract that applies if the builder fails to complete the project on time. The amount is usually calculated per day of delay and should reflect a genuine estimate of the homeowner’s potential loss. Queensland courts may rule excessive liquidated damages as unenforceable, so the agreed amount must be reasonable. Homeowners should include a liquidated damages clause in their contract to safeguard against project overruns.

How can builders protect themselves from delay-related disputes?

Builders should keep detailed records of all communications, site conditions, material deliveries, and project progress. Properly documenting weather disruptions, supply chain issues, and homeowner-caused delays can support EOT claims and defend against liquidated damages. To avoid potential liability, builders must submit EOT requests on time and ensure that all contractual obligations are met. In the event of a dispute, seeking mediation through the QBCC before escalating to QCAT can help resolve issues efficiently.

Can a homeowner terminate a contract due to excessive delays?

Yes, a homeowner may have the right to terminate the contract if delays are prolonged, unreasonable, and not excused by an EOT. Before terminating, they must follow the contract’s dispute resolution procedures, including giving the builder formal notice and an opportunity to rectify the delay. If the contract includes a termination clause for excessive delays, this will determine the proper legal process. Seeking legal advice before terminating can prevent wrongful termination claims from the builder.

How can construction delays be prevented?

Delays can be minimised by establishing clear timelines, maintaining strong communication, and managing risks proactively. Homeowners should ensure that design approvals, material selections, and payments are made on time to avoid unnecessary hold-ups. Builders should implement effective project management strategies, such as scheduling trades efficiently and securing materials in advance. Both parties should consider alternative dispute resolution methods (ADR) to resolve potential delays before they escalate into costly legal disputes.

What role does the QBCC play in resolving construction disputes?

The Queensland Building and Construction Commission (QBCC) provides mediation services for homeowners and builders to resolve disputes before taking legal action. If an agreement cannot be reached, the QBCC may issue a binding decision or refer the matter to QCAT. The QBCC can also discipline builders who repeatedly fail to meet contractual obligations, including suspending licences. Homeowners and builders should attempt to resolve disputes through the QBCC before escalating the matter to court.

How does QCAT handle construction delay disputes?

The Queensland Civil and Administrative Tribunal (QCAT) hears residential construction disputes, including claims for delays, liquidated damages, and contract breaches. It can award compensation, enforce EOTs, and terminate contracts if necessary. Before filing a claim, parties must first attempt mediation through the QBCC. QCAT provides a cost-effective alternative to litigation, making it a preferred forum for resolving delay-related disputes.

What are the risks of not correctly claiming an EOT?

If a builder fails to properly claim an extension of time, they risk being held liable for delay-related damages. If the project is significantly delayed, the homeowner may enforce liquidated damages or seek contract termination. Without proper documentation, the builder may lose the ability to defend against liability claims under the Prevention Principle. Ensuring EOT claims are submitted correctly and within the contract’s timeframe is essential to avoid financial penalties.

What should homeowners and builders do if a delay dispute arises?

Both parties should first attempt to resolve the issue through open communication and negotiation. If unresolved, mediation through the QBCC can help reach an agreement without escalating to QCAT or court proceedings. If mediation fails, the dispute may be referred to QCAT for a legally binding decision. Seeking legal advice early can help homeowners and builders understand their rights and obligations before pursuing legal action.

What are delay damages in construction?

Delay damages are financial compensation claimed when a construction project exceeds the agreed completion date without a valid extension of time (EOT). These damages compensate the affected party—typically the homeowner or developer—for financial losses caused by the delay, such as extra rent, mortgage payments, or business losses. Delay damages can be pre-agreed (liquidated damages) or assessed based on actual financial loss (general damages). To successfully claim delay damages, the contract must outline explicit provisions for delays, and the affected party must prove the economic impact of the delay.

What is the difference between liquidated damages and delay damages?

Liquidated damages are a pre-agreed fixed amount set in the construction contract, payable if the builder fails to complete the project on time. These damages are typically calculated daily or weekly, making it easier to enforce and reducing disputes over compensation amounts. Delay damages, on the other hand, refer to general compensation for actual financial losses suffered due to a project delay. Unlike liquidated damages, delay damages require the affected party to prove their losses, such as additional rent, lost income, or storage costs.

Can you charge a builder for taking too long?

Yes, suppose a builder fails to complete the project within the agreed timeframe and does not have a valid EOT. In that case, the homeowner may be entitled to liquidated damages or general damages. Liquidated damages can be enforced if the contract includes a specific clause outlining a fixed penalty for each day of delay. If no such clause exists, the homeowner may still claim general damages, but they must prove actual financial losses resulting from the delay. If a dispute arises, homeowners can seek mediation through the Queensland Building and Construction Commission (QBCC) or escalate the matter to QCAT.

What is a delay in construction contracts?

A delay in a construction contract occurs when the project does not progress according to the agreed timeline, causing completion to extend beyond the scheduled date. Delays can be excusable (e.g., extreme weather, supply shortages, unforeseen site conditions) or non-excusable (e.g., poor project management, builder mismanagement, subcontractor issues). The contract typically defines how delays are handled, including whether the builder can claim an EOT or if the homeowner is entitled to compensation for late completion. Proper documentation and adherence to contractual notice requirements are crucial in managing delays and avoiding disputes.

What are the most common causes of construction delays in Queensland?

Unforeseen site conditions, extreme weather events, supply chain disruptions, and contractual disputes can cause construction delays. Homeowner-requested design variations, council approval delays, and late progress payments can also contribute to project setbacks. Builders may also face labour shortages, material unavailability, or errors in architectural plans that impact the timeline. Understanding the cause of a delay is crucial in determining whether an extension of time (EOT) can be granted and if compensation applies.

When is a builder entitled to an extension of time (EOT)?

A builder is entitled to an EOT if the delay is caused by circumstances beyond their control, such as extreme weather, supply shortages, or council approval delays. To qualify, the delay must be excusable and meet contract provisions, and the builder must notify the homeowner in writing within the required timeframe. The claim should accompany supporting evidence, such as weather reports or supplier notices. If the builder fails to follow the correct procedure, the EOT may be rejected, leading to potential liability for liquidated damages.

What happens if a builder fails to complete the project on time?

If a builder does not meet the Date for Practical Completion and has not been granted an EOT, they may be liable for liquidated damages as outlined in the contract. The homeowner may also claim general damages if they can prove actual financial losses, such as increased rent or storage costs. In severe cases of prolonged delays, the homeowner may have the right to terminate the contract and seek further compensation. Builders who experience unavoidable delays should follow proper documentation and notification procedures to avoid financial penalties.

Can homeowners claim compensation for construction delays?

Yes, homeowners may claim liquidated damages if the contract specifies a pre-agreed daily penalty for late completion. If no liquidated damages clause exists, they may seek general damages, but they must prove actual financial loss due to the delay. Compensation claims depend on whether the delay is excusable or non-excusable and whether the builder has followed contractual obligations. If disputes arise, homeowners can lodge a complaint with the QBCC or escalate the matter to QCAT for resolution.

What is the Prevention Principle, and how does it affect construction delays?

The Prevention Principle states that a party cannot enforce contract penalties for a delay they caused. If a homeowner fails to approve design variations, delays material selections, or restricts site access, they may be prevented from claiming liquidated damages against the builder. In such cases, time may be set “at large,” meaning the builder is only required to complete the project within a reasonable timeframe rather than the original deadline. To avoid disputes, builders should document all delays caused by the homeowner and formally request an EOT.

How do supply chain disruptions impact construction contracts?

Material shortages and delivery delays can halt construction progress and create unexpected costs for builders and homeowners. Under Queensland construction law, supply chain disruptions may qualify for an EOT if unforeseeable and beyond the builder’s control. However, the builder may not be entitled to an extension if the delay was foreseeable when signing the contract. Builders should document supplier notices and attempts to source alternative materials to support any EOT claims.

What should be included in a construction contract to manage delays?

A well-drafted contract should include clear provisions for delays, outlining when extensions of time (EOTs) apply and whether liquidated damages will be enforced. It should also specify notification requirements, such as how and when the builder must inform the homeowner of a delay. The contract should define approvals, material selections, and site access responsibilities to prevent disputes over delay claims. Having a construction lawyer review the contract before signing can protect both parties’ rights.

What are liquidated damages in construction contracts?

Liquidated damages are a pre-agreed financial penalty set in the contract that applies if the builder fails to complete the project on time. The amount is usually calculated per day of delay and should reflect a genuine estimate of the homeowner’s potential loss. Queensland courts may rule excessive liquidated damages as unenforceable, so the agreed amount must be reasonable. Homeowners should include a liquidated damages clause in their contract to safeguard against project overruns.

How can builders protect themselves from delay-related disputes?

Builders should keep detailed records of all communications, site conditions, material deliveries, and project progress. Properly documenting weather disruptions, supply chain issues, and homeowner-caused delays can support EOT claims and defend against liquidated damages. To avoid potential liability, builders must submit EOT requests on time and ensure that all contractual obligations are met. In the event of a dispute, seeking mediation through the QBCC before escalating to QCAT can help resolve issues efficiently.

Can a homeowner terminate a contract due to excessive delays?

Yes, a homeowner may have the right to terminate the contract if delays are prolonged, unreasonable, and not excused by an EOT. Before terminating, they must follow the contract’s dispute resolution procedures, including giving the builder formal notice and an opportunity to rectify the delay. If the contract includes a termination clause for excessive delays, this will determine the proper legal process. Seeking legal advice before terminating can prevent wrongful termination claims from the builder.

How can construction delays be prevented?

Delays can be minimised by establishing clear timelines, maintaining strong communication, and managing risks proactively. Homeowners should ensure that design approvals, material selections, and payments are made on time to avoid unnecessary hold-ups. Builders should implement effective project management strategies, such as scheduling trades efficiently and securing materials in advance. Both parties should consider alternative dispute resolution methods (ADR) to resolve potential delays before they escalate into costly legal disputes.

What role does the QBCC play in resolving construction disputes?

The Queensland Building and Construction Commission (QBCC) provides mediation services for homeowners and builders to resolve disputes before taking legal action. If an agreement cannot be reached, the QBCC may issue a binding decision or refer the matter to QCAT. The QBCC can also discipline builders who repeatedly fail to meet contractual obligations, including suspending licences. Homeowners and builders should attempt to resolve disputes through the QBCC before escalating the matter to court.

How does QCAT handle construction delay disputes?

The Queensland Civil and Administrative Tribunal (QCAT) hears residential construction disputes, including claims for delays, liquidated damages, and contract breaches. It can award compensation, enforce EOTs, and terminate contracts if necessary. Before filing a claim, parties must first attempt mediation through the QBCC. QCAT provides a cost-effective alternative to litigation, making it a preferred forum for resolving delay-related disputes.

Category: Construction Law

Delays in Construction Contracts – Complete Guide - Building and Construction Lawyer

Delays in Construction Contracts in Qld – Complete Guide

Delays in Construction Contracts in Queensland Delays in construction contracts can have significant legal, financial, and practical consequences for both homeowners and builders in Queensland.

Who is an Influential Person for a Construction Company in Qld?

Who is an Influential Person for a Construction Company? An ‘influential person’ in a construction company is someone with significant sway or control over the

Builder gone bust in Queensland - bankrupt and liquidation - residential construction contract

Builder Gone Bust in Queensland? – Everything You Need to Know!

Has you builder gone bust in Queensland? The term “gone bust” refers to liquidation if your builder is a company (XYZ Pty Ltd, for example);

person in black leather jacket holding brown and black hiking shoes

Do I have to let the Builder Back on Site to Rectify Defective Work?

A common question we get asked quite regularly is “Do I have to let the builder back on site to rectify defective work?” Obviously, if

Male builder with instrument in apartment

Defective Building Work in Queensland – Complete Guide

Are you a property owner in Queensland with defective building work? If so, you may be quite frustrated and find it difficult to manage your

QBCC Licence Suspension / Cancellation for an Indictable Offence

QBCC license suspension or cancellation policy means that the QBCC can suspend or cancel a building license if the builder commits an indictable offence. An

Price Increase Clauses in Building Contracts – Are they Unfair?

Price Increase clauses are clauses in a building and construction contract which allows the builder to ‘unilaterally’ vary the price of the fixed-price residential building

Black wooden gavel with golden strip on table near stack of folders in courthouse

Repudiation of a Building Contract – Addinos v OJ Pippin Homes

Repudiation of a building contract occurs when one party evinces an intention no longer to be bound by the contract. In a recent decision of

Instruments prepared for measurements in house

Copyright in Building Plans after Termination of Building Contract

What happens to the copyright in building plans after termination of the residential building contract? A question that we get asked a lot is if

Reviewing a BIFA Adjudication Decision – #1 Complete Guide

Reviewing a BIFA adjudication decision is an option for a party who believes that there has been jurisdictional error, including a lack of procedural fairness

Terminating a Residential Building Contract in Queensland

Are you thinking about terminating a residential building contract in Queensland? Terminating a residential building contract does not come without its share of risk and

Crop repairman standing with working screwdriver and orange helmet

Builders Subcontractors’ Charge – Get Paid & Protect Yourself

A builders subcontractors’ charge can help a subcontractor get paid if the building contractor goes into liquidation. With the rise of building companies going into

Banknotes with a Portrait of a Lady Printed

Price Increases in Fixed Price Building Contracts Qld

Price increases in fixed fee building contracts are becoming a significant problem in building and construction law. We get asked almost every day “can my

Building Disputes lawyers in Queensland - Stonegate Legal

How to Avoid and Manage Building Disputes in Queensland

Building disputes can arise in a number of different ways between a number of different parties. A building dispute can be between a building owner

How to Draft an Adjudication Response in Queensland

If you want to know how to draft and serve an adjudication response, then this article will provide you with useful information. If you have

Discuss Your Case With A Trusted Lawyer

We approach your dispute with – strategic thinking, commercial solutions & positive outcomes.Our honest process is designed to get you the best commercially sensible resolution

Quick Links

Individual liability limited by a scheme approved under professional standards legislation.

Litigation Services

Monday – Friday
8:30 AM – 5:00 PM

Level 10/ 95 North Quay,
Brisbane City, QLD 4000 – (appointment only)

4/57-59 Mary Street,
Noosaville, QLD 4566

At Stonegate Legal, client satisfaction is our top priority. We are proud to have served hundreds of clients who have had positive experiences working with us.

Litigation Services

Category: Construction Law

Delays in Construction Contracts in Qld – Complete Guide

Who is an Influential Person for a Construction Company in Qld?

Builder Gone Bust in Queensland? – Everything You Need to Know!

Do I have to let the Builder Back on Site to Rectify Defective Work?

Defective Building Work in Queensland – Complete Guide

QBCC Licence Suspension / Cancellation for an Indictable Offence

Price Increase Clauses in Building Contracts – Are they Unfair?

Repudiation of a Building Contract – Addinos v OJ Pippin Homes

Copyright in Building Plans after Termination of Building Contract

Reviewing a BIFA Adjudication Decision – #1 Complete Guide

Terminating a Residential Building Contract in Queensland

Builders Subcontractors’ Charge – Get Paid & Protect Yourself

Price Increases in Fixed Price Building Contracts Qld

How to Avoid and Manage Building Disputes in Queensland

How to Draft an Adjudication Response in Queensland

Claim A No Obligation Case Evaluation

Discuss Your Case With A Trusted Lawyer

Quick Links

Litigation Services

Home

News & Blogs

Contact Us